General Contractor Agreement
Date: [Start Date]
Parties
Owner: [Owner Name], of [Owner Address], [Owner City], [Owner State] [Owner Zip] (the "Owner")
Contractor: [Contractor Name], of [Contractor Address], [Contractor City], [Contractor State] [Contractor Zip] (the "Contractor")
Contractor License: [Contractor License]
1. Scope of Work
The Owner engages the Contractor, and the Contractor agrees, to perform the following work at the project site located at [Project Address] (the "Project"):
[Project Description]
The Contractor shall perform all work in a professional and workmanlike manner, in compliance with the applicable state and local building codes, all municipal ordinances, zoning regulations, and applicable federal regulations including OSHA workplace safety standards (29 CFR 1926). The Contractor shall obtain all necessary building permits, inspections, and approvals at the Contractor's expense, unless otherwise agreed in writing.
2. Project Timeline
Estimated Start Date: [Start Date]
Estimated Completion Date: [Completion Date]
The Contractor shall use commercially reasonable efforts to complete the Project by the estimated completion date. Delays caused by force majeure events, acts of God, government-ordered shutdowns, supply chain disruptions, unusually severe weather, or conditions beyond the Contractor's reasonable control shall extend the completion date by an equivalent period, provided the Contractor promptly notifies the Owner in writing.
3. Contract Price and Payment
The Owner agrees to pay the Contractor USD $[Contract Price] for the complete performance of the work described herein (the "Contract Price"). Applicable state and local sales taxes shall be added as required by law.
Payment Schedule: [Payment Schedule].
The Owner shall retain [Retainage Percentage]% of each progress payment as retainage. The retainage shall be released within thirty (30) days after the date of substantial completion, provided the Contractor has corrected all punch list items and delivered all required lien waivers. The parties acknowledge that state mechanic's lien statutes govern the right of contractors, subcontractors, and material suppliers to file liens against the property and may impose additional requirements regarding retainage and payment timelines.
4. Change Orders
Any changes to the scope of work, materials, or specifications must be agreed upon in writing by both parties through a formal change order before such work commences. A change order shall specify the nature of the change, the impact on the Contract Price, and the impact on the completion date. No additional work shall be performed, and no additional compensation shall be owed, without a signed change order.
5. Insurance and Workers' Compensation
The Contractor shall maintain, at its own expense, commercial general liability (CGL) insurance with a minimum coverage as required by the project and industry standards for the duration of the Project. The Owner shall be named as an additional insured on the Contractor's CGL policy.
The Contractor shall maintain workers' compensation insurance as required by the laws of the State of [Owner State]. The Contractor is solely responsible for all workers' compensation premiums for its employees and subcontractors. The Contractor shall provide certificates of insurance to the Owner prior to commencing work.
6. Mechanic's Liens
The Contractor shall take all reasonable steps to ensure that no mechanic's lien, materialman's lien, or construction lien is filed against the Owner's property as a result of the work performed under this Agreement. The Contractor shall provide unconditional lien waivers from all subcontractors and material suppliers with each progress payment application.
The Contractor shall indemnify and hold the Owner harmless from any lien claims arising from the Contractor's failure to pay subcontractors or material suppliers. The Contractor acknowledges that mechanic's lien rights and filing deadlines are governed by the laws of the State of [Owner State] and vary by jurisdiction. On federal projects, the Miller Act (40 U.S.C. 3131-3134) requires payment and performance bonds in lieu of lien rights; state Little Miller Acts impose similar requirements for state-funded projects.
7. Indemnification
The Contractor shall indemnify, defend, and hold harmless the Owner from and against any and all claims, damages, losses, costs, and expenses (including reasonable attorney's fees) arising out of or resulting from the Contractor's performance of the work, including but not limited to claims for personal injury, property damage, or death, except to the extent caused by the Owner's sole negligence or willful misconduct.
8. Warranties
The Contractor warrants that: (a) all work shall be performed in a good and workmanlike manner consistent with industry standards; (b) all materials supplied shall be new and of good quality unless otherwise specified; (c) the work shall comply with all applicable building codes, regulations, and standards; (d) the work shall be free from defects in materials and workmanship for a period of one (1) year from the date of substantial completion. The Contractor shall promptly repair or replace any defective work at no additional cost to the Owner during the warranty period.
9. Termination
Either party may terminate this Agreement upon fourteen (14) days' written notice if the other party commits a material breach and fails to cure such breach within fourteen (14) days of receiving written notice. The Owner may terminate this Agreement for convenience upon thirty (30) days' written notice. Upon termination, the Owner shall pay the Contractor for all work satisfactorily completed to the date of termination, less any retainage and any damages caused by the Contractor's breach.
10. Dispute Resolution
Any dispute arising under this Agreement shall first be submitted to mediation administered by a mutually agreed-upon mediator. If mediation fails to resolve the dispute within thirty (30) days, either party may pursue binding arbitration or litigation in the courts of the State of [Owner State]. The prevailing party shall be entitled to recover reasonable attorney's fees and costs.
11. Governing Law
This Agreement shall be governed by and construed in accordance with the laws of the State of [Owner State]. Any legal action arising under this Agreement shall be filed in the state or federal courts located within the State of [Owner State].
Owner
________________
Signature
Contractor
________________
Signature
What Is a General Contractor Agreement?
A General Contractor Agreement in the United States records the obligations, timelines and payment owed between the client and the service provider.
U.S. construction law is regulated primarily at the state level, with significant federal requirements layered on top. Each state has its own mechanic's lien statute — California's Civil Code Sections 8000-8848, New York's Lien Law Article 2, Texas Property Code Chapter 53, and Florida Statutes Chapter 713 — that governs the right of contractors, subcontractors, and material suppliers to file liens against real property when they are not paid. These statutes impose notice requirements, filing deadlines, and in some cases mandatory retainage obligations that directly affect how the general contractor agreement must be structured.
Federal requirements include OSHA construction safety standards (29 CFR 1926), which apply to all construction sites and hold general contractors responsible for worksite safety under the multi-employer worksite doctrine. For federally funded projects, the Davis-Bacon Act (40 U.S.C. 3141-3148) requires payment of prevailing wages to laborers and mechanics, and the Miller Act (40 U.S.C. 3131-3134) requires performance and payment bonds. State Little Miller Acts impose similar requirements for state-funded projects.
The agreement also establishes whether the contractor relationship is fixed-price, cost-plus, or time-and-materials, each carrying different risk profiles for both parties. The IRS independent contractor test (common law factors under Rev. Rul. 87-41) determines whether the contractor is properly classified as an independent contractor rather than an employee for tax purposes.
When Do You Need a General Contractor Agreement?
When hiring a general contractor for a home renovation exceeding $5,000, where multiple trades (electrical, plumbing, framing, HVAC) will be coordinated under one project manager and the work requires building permits from the local authority having jurisdiction.
When building a new residential or commercial structure that requires compliance with the International Building Code (IBC) as adopted by the state, municipal permits, inspections, and certificates of occupancy.
When a property owner needs to formalize the contractor's obligation to carry commercial general liability (CGL) insurance, workers' compensation insurance, and provide certificates of insurance naming the owner as additional insured before work begins.
When the project involves subcontractors, and the owner needs contractual protection against mechanic's liens through retainage withholding, lien waiver requirements, and indemnification provisions.
When converting or renovating a commercial space where the lease requires landlord approval, the contractor must comply with specific ADA accessibility standards (28 CFR 36), and the work must meet fire code and energy code requirements.
When the project is on federal or state-funded property requiring compliance with the Miller Act, Davis-Bacon Act prevailing wages, or state Little Miller Act bonding requirements.
Skipping a written general contractor agreement exposes the property owner to uncontrolled costs, mechanic's lien claims from unpaid subcontractors, liability for worksite injuries, no enforceable warranty on completed work, and potentially paying for work that fails to meet building code requirements.
What to Include in Your General Contractor Agreement
Scope of Work and Specifications — A detailed description of all work to be performed, materials to be used, and applicable building codes. Vague scope descriptions are the leading cause of construction disputes in American courts and arbitration proceedings.
Payment Schedule and Retainage — Progress payment milestones tied to completion stages, with the retainage percentage (typically 5-10%) clearly stated. Some states cap retainage: California limits it to 5% on private projects (Civil Code 8814). Retainage is released after substantial completion, punch list correction, and delivery of final lien waivers.
Change Order Procedures — A formal process requiring written approval before any changes to scope, timeline, or cost. Without this, contractors may claim additional compensation for work the owner considered included in the original price, leading to costly disputes.
Insurance and Workers' Compensation — The contractor must maintain CGL insurance (minimum $1-2 million per occurrence), workers' compensation as required by state law, and commercial auto liability. The owner should be named as additional insured. Workers' compensation is mandatory in 49 states (Texas is the exception for private employers).
Mechanic's Lien Protection — Retainage withholding, unconditional lien waiver requirements with each payment application, and contractor indemnification against lien claims from subcontractors and suppliers.
Project Timeline and Delay Provisions — Start date, milestone dates, and substantial completion date, with provisions for force majeure, weather delays, and supply chain disruptions. Liquidated damages clauses for unjustified delays are common in commercial contracts.
Warranty and Deficiency Provisions — A minimum one-year warranty on workmanship with a clear deficiency correction procedure. Implied warranties of habitability and fitness may apply under state law even if not expressly stated in the contract.
Dispute Resolution — Specify mediation followed by binding arbitration or litigation. Construction arbitration is widely used and can save significant legal costs compared to court proceedings.
Termination Clauses — Conditions for termination for cause (material breach) and for convenience (owner's discretion), with payment procedures for work completed prior to termination.
Sources & Citations
Statutory citations link to official government sources.
- 40 U.S.C. 3141US – Cornell LII
- 40 U.S.C. 3131US – Cornell LII
- 29 CFR 1926US – eCFR
- 28 CFR 36US – eCFR
- ADAUS – Cornell LII
Cite this page
Reference this free template in an article, syllabus, or research note:
Forms Legal. (2026). General Contractor Agreement (United States) [Legal document template]. Forms Legal. https://forms-legal.com/usa/business/contracts/general-contractor-agreement
"General Contractor Agreement (United States)." Forms Legal, 2026, https://forms-legal.com/usa/business/contracts/general-contractor-agreement.
@misc{formslegal-general-contractor-agreement,
author = {{Forms Legal}},
title = {General Contractor Agreement (United States)},
year = {2026},
howpublished = {\url{https://forms-legal.com/usa/business/contracts/general-contractor-agreement}},
note = {Free legal document template. Based on Uniform Commercial Code (UCC)}
}Also available for these jurisdictions:
Frequently Asked Questions
A general contractor agreement is legally binding once the parties sign it and the basic elements of a contract are present, including offer, acceptance, consideration, mutual intent, and a lawful purpose. The agreement governs the relationship between a property owner and a general contractor for a construction or renovation project, setting out the scope of work, the price, the schedule, and each party's responsibilities. The agreement should clearly state the parties' obligations and the key terms, and it must comply with applicable federal and state law. While some agreements can be oral, a written contract is far easier to enforce, and certain agreements must be in writing under the statute of frauds. Because disputes turn on what the parties agreed, a clear, signed written agreement provides the strongest protection, defining each party's rights and obligations and how problems will be handled. Both parties should review the terms carefully before signing to ensure the agreement reflects their understanding and protects their interests. For significant matters, legal review helps confirm the agreement is enforceable and complete. A well-drafted general contractor agreement reduces misunderstandings and gives the parties a reliable framework for their relationship and obligations.
A general contractor agreement should include the scope of work, the contract price and payment structure, the project schedule, the responsibilities of each party, and provisions for changes, warranties, insurance, and dispute resolution. The scope of work should describe the project in detail, often referencing plans and specifications, and the price section should state whether it is a fixed price, cost plus a fee, or another structure, with a payment schedule tied to milestones or progress. The agreement should address change orders for modifications, the contractor's obligation to obtain permits and comply with building codes, lien waiver procedures to protect the owner from subcontractor and supplier claims, warranties on the work, and insurance and bonding requirements. Termination provisions and dispute resolution mechanisms are also important. Because construction projects involve significant cost and risk of delays and defects, a clear agreement protects both parties. A well-drafted general contractor agreement defines the work, the price, the schedule, and the responsibilities, reducing disputes and giving the owner and contractor a clear framework for completing the project.
A general contractor generally needs to be licensed and insured, with the specific requirements depending on the state, locality, and the size of the project. Most states require general contractors to hold a license for construction work above a certain value, and performing unlicensed work can make the contract unenforceable in some states and expose the contractor to penalties. Contractors should also carry general liability insurance to cover property damage and injuries, and workers' compensation insurance where they have employees, and the agreement should require proof of coverage through certificates of insurance. Larger projects may require the contractor to provide a surety bond guaranteeing performance and payment to subcontractors and suppliers. The agreement should also address responsibility for obtaining building permits and complying with codes. Because hiring an unlicensed or uninsured contractor creates significant legal and financial risk for the owner, the general contractor agreement should require the contractor to maintain the appropriate licenses, insurance, and bonding, and to provide documentation before work begins, protecting the owner if problems or claims arise during the project.
Payments in a general contractor agreement are typically structured to align with the project's progress, protecting both the owner and the contractor. Common structures include progress payments tied to completion milestones or a percentage of work finished, an initial deposit to begin work, and a retainage, in which the owner withholds a percentage of each payment until the project is satisfactorily completed, giving the contractor an incentive to finish and correct defects. The payment schedule should specify the amounts, the milestones or schedule for each payment, and any documentation, such as lien waivers from the contractor, subcontractors, and suppliers, required before payment is released. The agreement may use a fixed price, cost-plus, or unit-price method, which affects how amounts are calculated. Because payment disputes are common in construction, a clear schedule with defined milestones, retainage, and lien waiver requirements helps ensure the contractor is paid fairly and the owner receives the agreed work. A general contractor agreement should set out the payment structure precisely so both parties understand when and how much is paid as the project advances toward completion.
If a contractor does not finish the work or performs it poorly, the owner's remedies depend on the general contractor agreement and the circumstances, and may include withholding payment, terminating the contract, and pursuing damages. The agreement should define what constitutes a default, such as failing to perform, abandoning the project, or substandard work, and the owner's remedies, including the right to terminate for cause after notice and an opportunity to cure. If the contractor breaches, the owner may withhold further payment, hire another contractor to complete or correct the work, and seek damages for the additional cost, and any retainage withheld helps cover completion costs. The contractor's insurance or bond may provide recovery. The owner generally must follow the agreement's termination and notice provisions and may need to document the deficiencies. Because disputes over incomplete or defective work are common, the agreement's provisions on default, termination, warranties, and remedies govern the owner's options. A general contractor agreement that clearly addresses what happens if the contractor fails to perform protects the owner and provides a path to complete the project and recover losses.
Read Our Step-by-Step Guide
Learn how to create a professional General Contractor Agreement with our detailed guide, including key tips and common mistakes to avoid.
Read the full guideThis template is provided for informational purposes only and does not constitute legal advice. Laws vary by jurisdiction and change over time. Consult a qualified attorney for advice specific to your situation.Full disclaimer
Found an error? Let us knowRelated Documents
You may also find these documents useful:
Independent Contractor Agreement
Hiring a freelance designer, a marketing consultant, or a software developer? An Independent Contractor Agreement makes clear they're not an employee — and that matters for taxes, liability, and IP ownership. It lays out the deliverables, payment terms, deadlines, and who owns the finished work. Our template includes clauses for confidentiality, non-solicitation, termination, and dispute resolution. Enter the details, preview your document in real time, and download a clean PDF or Word file — free, no account required.
Service Contract
Hiring someone for a project or offering your services to a client? A service contract keeps everyone on the same page about what's being done, when it's due, and how much it costs. It covers the scope of work, timeline, payment terms, revision policies, confidentiality obligations, and what happens if either party wants to walk away. Whether you're a freelancer, small business owner, or corporate manager, this template helps you avoid the most common disputes—scope creep, late payments, and unclear expectations. Covers termination clauses, liability limits, intellectual property ownership, and dispute resolution. Free PDF and Word—generate in minutes, no account needed.
Subcontractor Agreement
Hired a subcontractor to help with a project? You're still on the hook with your client, so the sub's work needs to be clearly defined. A Subcontractor Agreement covers the scope of work, payment terms, deadlines, quality standards, insurance requirements, and who owns the intellectual property. It also addresses what happens if the sub misses deadlines or delivers subpar work. Protect your reputation and your bottom line. Our free template covers all the critical terms. Fill it out, preview, and download as PDF or Word.