Construction Loan Agreement (Ghana)
Construction Loan Agreement
This Construction Loan Agreement (this "Agreement") is entered into on [Agreement Date] between:
LENDER: [Lender Name], a bank or specialised deposit-taking institution licensed by the Bank of Ghana under the Banks and Specialised Deposit-Taking Institutions Act 2016 (Act 930), having its registered office at [Lender Address] (the "Lender"); and
BORROWER: [Borrower Name], company registration number [Borrower Reg Number], of [Borrower Address] (the "Borrower").
The Lender and the Borrower are collectively referred to as the "Parties".
Recitals
The Borrower intends to carry out the following construction project: [Project Description] (the "Project") on land with title reference [Land Title Number] registered at the Lands Commission under the Land Act 2020 (Act 1036).
The Borrower has requested the Lender to advance a construction loan facility to finance the Project, and the Lender has agreed to do so on the terms set out in this Agreement.
1. Construction Loan Facility
Subject to the terms and conditions of this Agreement, the Lender agrees to make available to the Borrower a construction loan facility of GHS [Facility Amount] (the "Facility") for the purpose of financing the Project.
The Facility shall be disbursed in [Number Of Drawdowns] tranches in accordance with the drawdown schedule set out in Clause 3 of this Agreement.
The Facility is made available under and subject to the Banks and Specialised Deposit-Taking Institutions Act 2016 (Act 930) and the Borrowers and Lenders Act 2020 (Act 1052).
The estimated date for practical completion of the Project is [Completion Date].
2. Interest Rate and Fees
Interest shall accrue on the outstanding drawn balance at the rate of [Interest Rate]% per annum ([Interest Type]) from the date of the first drawdown.
During the construction period, interest shall be charged on drawn amounts only. Capitalisation of construction period interest is subject to written agreement between the Parties.
An arrangement fee of GHS [Arrangement Fee] shall be payable by the Borrower on execution of this Agreement.
The Borrower shall repay the Facility in full over [Repayment Period] commencing on the date of practical completion of the Project, or on such conversion date as the Parties agree in writing pursuant to the Mortgage Finance Act 2008 (Act 770).
3. Drawdown Schedule and Conditions
The Borrower may request drawdowns in accordance with the following milestone conditions: [Drawdown Conditions].
Each drawdown request must be accompanied by: (a) a written drawdown notice signed by the Borrower; (b) a progress certificate issued by a licensed quantity surveyor confirming that the relevant construction milestone has been achieved; and (c) such other documents as the Lender may reasonably require.
The Lender may conduct a site inspection prior to releasing each drawdown tranche and may withhold any tranche if the progress certificate is not supported by physical inspection findings.
4. Security
As security for repayment of the Facility, the Borrower charges in favour of the Lender: [Security Description].
The security shall be registered at the Lands Commission under the Land Act 2020 (Act 1036) and in the Collateral Registry maintained by the Bank of Ghana under the Borrowers and Lenders Act 2020 (Act 1052) before the first drawdown is released.
The guarantee of [Guarantor Name] shall be provided in a form acceptable to the Lender prior to first drawdown.
5. Events of Default
Each of the following constitutes an event of default: (a) the Borrower fails to pay any amount due under this Agreement on its due date; (b) the Borrower becomes insolvent or unable to pay its debts as they fall due; (c) the Borrower abandons the Project; (d) the Borrower breaches any material term of this Agreement and fails to remedy such breach within 30 days of written notice.
On the occurrence of an event of default, the Lender may enforce its security in accordance with the procedures prescribed by the Borrowers and Lenders Act 2020 (Act 1052) and the Mortgage Finance Act 2008 (Act 770).
6. Governing Law and Dispute Resolution
This Agreement is governed by the laws of the Republic of Ghana, including the Banks and Specialised Deposit-Taking Institutions Act 2016 (Act 930), the Borrowers and Lenders Act 2020 (Act 1052), and the Land Act 2020 (Act 1036).
Any dispute arising out of or in connection with this Agreement shall be referred to [Dispute Resolution].
Signatures
IN WITNESS WHEREOF the Parties have executed this Construction Loan Agreement on the date first written above.
Lender
________________
Signature
Borrower
________________
Signature
What Is a Construction Loan Agreement (Ghana)?
A Construction Loan Agreement in Ghana sets the principal, interest, repayment schedule and security governing a loan between lender and borrower.
Construction lending in Ghana is regulated primarily by the Banks and Specialised Deposit-Taking Institutions Act 2016 (Act 930), which governs banks and specialised deposit-taking institutions (SDIs) licensed by the Bank of Ghana (BoG). The Bank of Ghana, established under the Bank of Ghana Act 2002 (Act 612), is the prudential regulator for all deposit-taking financial institutions in Ghana and sets capital adequacy requirements, lending limits, and credit concentration rules applicable to construction lending. Section 1 of Act 930 defines the scope of regulated deposit-taking business and provides the legal foundation for credit facilities advanced by licensed banks and SDIs.
The Mortgage Finance Act 2008 (Act 770) provides additional regulation for mortgage-backed construction lending in Ghana, establishing the legal framework under which land or buildings may be charged as security for a construction loan. The Land Act 2020 (Act 1036) governs the registration of charges over land at the Lands Commission, replacing earlier legislation and modernising the process for creating and registering security interests in Ghanaian land. Section 122 of the Land Act 2020 (Act 1036) deals with the creation of mortgages over freehold and leasehold interests.
The Borrowers and Lenders Act 2020 (Act 1052) further regulates credit transactions in Ghana and establishes the Collateral Registry, administered by the Bank of Ghana, where security interests in movable and immovable property must be registered to be effective against third parties. Lenders and borrowers should register any charge created under a Construction Loan Agreement in the Collateral Registry under Act 1052 to protect priority against competing creditors.
A Construction Loan Agreement in Ghana typically incorporates a quantity surveyor's certificate or progress certificate issued by a licensed professional under the Ghana Institution of Surveyors as a precondition for each drawdown. The interest rate may be fixed or variable and must comply with the Bank of Ghana's published base rate and any caps on lending rates prescribed by the BoG. All interest income earned by the lender is subject to income tax under the Income Tax Act 2015 (Act 896), and withholding tax on interest payments may apply depending on the borrower's tax status as determined by the Ghana Revenue Authority (GRA).
A Construction Loan Agreement (Ghana) is distinct from a project finance agreement, a bridging loan, and a standard mortgage. Construction loan facilities are typically converted to a term mortgage on practical completion of the building, at which point the loan is refinanced as a long-term mortgage under the Mortgage Finance Act 2008 (Act 770). The forms-legal.com template provides a compliant starting point for negotiating construction financing in Ghana's regulated banking sector.
When Do You Need a Construction Loan Agreement (Ghana)?
A Construction Loan Agreement in Ghana is required in the following circumstances.
A Construction Loan Agreement is needed when an individual or company intends to finance the development of residential, commercial, or industrial property in Ghana and requires staged disbursements from a bank or SDI licensed by the Bank of Ghana under the Banks and Specialised Deposit-Taking Institutions Act 2016 (Act 930). Without a written agreement setting out drawdown conditions, both the lender and the borrower face significant financial and legal exposure.
A Construction Loan Agreement is required when a property developer in Accra, Kumasi, Takoradi, or any other city in Ghana's 16 administrative regions seeks construction finance from a universal bank such as GCB Bank, Ecobank Ghana, or Absa Bank Ghana, and the lender needs a legally enforceable disbursement schedule tied to building progress reports from a certified quantity surveyor.
A Construction Loan Agreement is needed when the borrower is pledging land held under a registered freehold title or leasehold registered at the Lands Commission as security for the facility. The Mortgage Finance Act 2008 (Act 770) requires that the charge over the land be created by a formal deed and registered at the Lands Commission to be effective against third parties, and the Construction Loan Agreement must describe the security interest to enable registration under the Land Act 2020 (Act 1036).
A Construction Loan Agreement is required when a real estate investment company or special purpose vehicle (SPV) incorporated under the Companies Act 2019 (Act 992) and registered with the Office of the Registrar of Companies (ORC) is developing residential estates or mixed-use projects in Ghana and requires a facility that distinguishes between land acquisition funding, construction funding, and post-completion mortgage funding.
A Construction Loan Agreement is needed where the project involves a public-private partnership (PPP) with a district assembly or metropolitan authority in Ghana, as the Public Procurement Authority (PPA) and the Ministry of Finance require formal financing agreements to approve project budgets and drawdown schedules.
Parties in Ghana should execute a Construction Loan Agreement before any construction work commences and before any funds are advanced. Executing the agreement after disbursements have begun creates uncertainty about the terms under which money was advanced and may render the lender's security unenforceable. The Borrowers and Lenders Act 2020 (Act 1052) requires lenders to register credit agreements above prescribed thresholds with the Collateral Registry, and delays in execution delay registration, potentially prejudicing the lender's priority.
What to Include in Your Construction Loan Agreement (Ghana)
A valid Construction Loan Agreement in Ghana under the Banks and Specialised Deposit-Taking Institutions Act 2016 (Act 930) and the Borrowers and Lenders Act 2020 (Act 1052) must contain the following essential elements.
Parties and Recitals: Full legal names of the lender (bank or SDI licensed by the Bank of Ghana) and the borrower (individual or company registered under the Companies Act 2019 - Act 992 with the Office of the Registrar of Companies), the lender's Bank of Ghana licence number, and the borrower's Ghana Card or passport number (for individuals) or company registration number (for entities). Recitals should describe the construction project, the site address, and the planning permission reference issued by the relevant district assembly or the Accra Metropolitan Assembly (AMA).
Facility Amount and Currency: The total construction loan facility in Ghana Cedis (GHS), confirmed as distinct from any separate land acquisition facility. All amounts must be expressed in GHS unless the borrower is a foreign-currency earner and the Bank of Ghana has approved a foreign currency facility.
Drawdown Schedule and Conditions: The number and timing of drawdowns, the milestone or stage of completion required to trigger each drawdown, the procedure for requesting a drawdown (including submission of a quantity surveyor's progress certificate), and the lender's right to conduct site inspections before releasing each tranche.
Interest Rate and Fees: The interest rate (fixed or variable), the reference rate (Bank of Ghana base rate or Ghana Reference Rate (GRR)), the margin above the reference rate, arrangement fees, commitment fees, and early repayment fees. The agreement must state the annual percentage rate (APR) in compliance with Bank of Ghana consumer protection directives.
Repayment Schedule: The repayment commencement date (typically after practical completion), the repayment period, the instalment amounts, and the procedure for converting the construction loan to a term mortgage under the Mortgage Finance Act 2008 (Act 770) on practical completion of the building.
Security: Description of the security, which typically includes a first legal mortgage or charge over the land and building registered at the Lands Commission under the Land Act 2020 (Act 1036), personal guarantees from the borrower's directors (if the borrower is a company), and assignment of the building contract and insurance policies. The security must be registered in the Collateral Registry under the Borrowers and Lenders Act 2020 (Act 1052).
Events of Default: Failure to meet repayment obligations, insolvency, material adverse change, breach of conditions precedent, or abandonment of the construction project. On an event of default, the lender must follow the enforcement procedures prescribed by the Borrowers and Lenders Act 2020 (Act 1052) before enforcing security.
Governing Law and Dispute Resolution: Ghana law, with disputes referred to the High Court (Commercial Division) in Accra, or arbitration under the Alternative Dispute Resolution Act 2010 (Act 798) administered by the Ghana Arbitration Centre. Forms-legal.com provides this Construction Loan Agreement (Ghana) template as a starting point for Ghana-compliant construction finance documentation.
Additional compliance elements for a Construction Loan Agreement (Ghana) used in Ghana include: Under the Banks and Specialised Deposit-Taking Institutions Act 2016 (Act 930), the Bank of Ghana (BoG) regulates banking. The Securities Industry Act 2016 (Act 929) and Securities and Exchange Commission (SEC Ghana) regulate capital markets. Section 48 of the Bills of Exchange Act 1961 (Act 55) governs promissory notes. The Ghana Revenue Authority (GRA) administers tax obligations. The National Insurance Commission (NIC) regulates insurance. Forms-legal.com provides this template as a starting point for Ghana-compliant documentation.
Cite this page
Reference this free template in an article, syllabus, or research note:
Forms Legal. (2026). Construction Loan Agreement (Ghana) (Ghana) [Legal document template]. Forms Legal. https://forms-legal.com/ghana/financial/loans/construction-loan-agreement-ghana
"Construction Loan Agreement (Ghana) (Ghana)." Forms Legal, 2026, https://forms-legal.com/ghana/financial/loans/construction-loan-agreement-ghana.
@misc{formslegal-construction-loan-agreement-ghana,
author = {{Forms Legal}},
title = {Construction Loan Agreement (Ghana) (Ghana)},
year = {2026},
howpublished = {\url{https://forms-legal.com/ghana/financial/loans/construction-loan-agreement-ghana}},
note = {Free legal document template}
}Frequently Asked Questions
Construction lending by banks and specialised deposit-taking institutions (SDIs) in Ghana is governed primarily by the Banks and Specialised Deposit-Taking Institutions Act 2016 (Act 930), which requires all banks and SDIs to be licensed by the Bank of Ghana and to comply with prudential guidelines on credit concentration, capital adequacy, and credit risk management. The Bank of Ghana, acting under Act 930 and the Bank of Ghana Act 2002 (Act 612), issues directives on lending rates, loan classification, and provisioning that apply to all construction loan portfolios. The Borrowers and Lenders Act 2020 (Act 1052) requires lenders to register credit agreements and security interests in the Collateral Registry. The Mortgage Finance Act 2008 (Act 770) governs mortgage-backed facilities, and the Land Act 2020 (Act 1036) governs the registration of charges over land at the Lands Commission. Together these statutes form the detailed regulatory framework for construction lending in Ghana.
Under a Construction Loan Agreement in Ghana, the total facility is not advanced in one lump sum. Instead, the borrower submits drawdown requests at defined stages of construction — typically tied to the completion of foundations, superstructure, roofing, and finishing. Each drawdown request must be accompanied by a progress certificate or quantity surveyor's certificate confirming that the relevant stage has been completed to the required standard. The lender's representative or an appointed monitoring surveyor conducts a site inspection before approving the release of each tranche. The Bank of Ghana's prudential guidelines require lenders to maintain adequate records of project monitoring for construction facilities. Funds are released directly to nominated contractors where the lender requires additional control over disbursements. Construction period interest is typically charged on the drawn-down balance only, with capitalisation of interest during construction subject to agreement between the parties.
A lender advancing a construction loan in Ghana under the Banks and Specialised Deposit-Taking Institutions Act 2016 (Act 930) typically requires: (1) a first legal mortgage or charge over the land and the building to be constructed, registered at the Lands Commission under the Land Act 2020 (Act 1036) and in the Collateral Registry under the Borrowers and Lenders Act 2020 (Act 1052); (2) an assignment of all rights under the building contract between the borrower and the main contractor; (3) an assignment of the contractor's all-risk insurance policy and property insurance; (4) personal guarantees from the directors or shareholders of the borrower company if the borrower is a company incorporated under the Companies Act 2019 (Act 992); and (5) a legal opinion from a Ghanaian solicitor enrolled with the Ghana Bar Association confirming the validity and enforceability of the security. The registration of security at the Lands Commission and in the Collateral Registry is essential to establish the lender's priority over competing creditors.
On practical completion of the construction project in Ghana — evidenced by a completion certificate issued by the building contractor and a certificate of practical completion confirmed by the quantity surveyor — the Construction Loan Agreement typically provides for automatic or optional conversion to a long-term mortgage under the Mortgage Finance Act 2008 (Act 770). The conversion involves refinancing the outstanding construction loan balance into a term repayment mortgage with a defined amortisation schedule, typically over 10 to 20 years. The existing charge over the land and building registered at the Lands Commission continues as security for the term mortgage without requiring re-registration, provided the original charge document was drafted to cover the converted facility. The borrower and lender sign a conversion deed or facility amendment letter confirming the new repayment terms, interest rate, and instalment amounts.
If a borrower defaults on a construction loan in Ghana, the lender must follow the enforcement procedures prescribed by the Borrowers and Lenders Act 2020 (Act 1052). The Act requires the lender to serve a formal demand notice on the borrower and guarantors specifying the amount outstanding and a reasonable period (typically not less than 30 days) to remedy the default. If the default is not remedied within the notice period, the lender may enforce the registered security by applying to the High Court (Commercial Division) in Accra for an order for sale or possession of the mortgaged property, or by exercising a private power of sale if expressly included in the mortgage deed and permitted by the Mortgage Finance Act 2008 (Act 770). The lender may also appoint a receiver over the project under the terms of the debenture. Lenders are prohibited from engaging in unlawful self-help remedies such as forcible eviction of the borrower, and such conduct may attract sanctions from the Bank of Ghana under Act 930.
This template is provided for informational purposes only and does not constitute legal advice. Laws vary by jurisdiction and change over time. Consult a qualified attorney for advice specific to your situation.Full disclaimer
Found an error? Let us knowRelated Documents
You may also find these documents useful:
Mortgage Agreement (Ghana)
A Mortgage Agreement for Ghana securing a loan against real property under the Mortgages Act 1972 (Act 392), the Land Act 2020 (Act 1036), and the Land Title Registration Act 1986 (PNDCL 152), with registration at the Lands Commission of Ghana.
Construction Contract (Ghana)
A formal Construction Contract for Ghana setting out obligations of the owner and contractor under the Contracts Act 1960 (Act 25), covering scope of works, payment schedule, variations, defects liability, and dispute resolution.