Service Contract for Landscaping Services (Australia)
This Service Contract for Landscaping Services (the “Contract”) is made on [Agreement Date] between:
[Landscaper Name] (ABN [Landscaper ABN]) of [Landscaper Address], [Landscaper Suburb], [Landscaper State] [Landscaper Postcode] (the “Landscaper”); and
[Client Name] (ABN [Client ABN]) of [Client Address], [Client Suburb], [Client State] [Client Postcode] (the “Client”).
The Landscaper and the Client are referred to collectively as the “Parties”.
BACKGROUND
A. The Client wishes to engage the Landscaper to perform landscaping services at the property described in this Contract.
B. The Landscaper has agreed to provide those services on the terms and conditions set out in this Contract, including compliance with applicable Australian work health and safety legislation.
C. This Contract is intended to comply with the Australian Consumer Law (Schedule 2 of the Competition and Consumer Act 2010 (Cth)), the Work Health and Safety Act 2011 (Cth) and its state and territory equivalents, and the general law of [Governing State].
NOW, THEREFORE, the Parties agree as follows:
1. LANDSCAPING SERVICES
1.1 The Landscaper agrees to perform [Engagement Type] at [Property Address] (the “Property”).
1.2 The scope of work is as follows:
[Scope Of Work]
1.3 Materials: [Materials Provision].
1.4 The Landscaper holds the following contractor licence (where required by state or territory law): [Landscaper Licence].
1.5 The Landscaper will perform all services with due care and skill and in a proper and workmanlike manner, using suitable materials and equipment, consistent with the consumer guarantees implied by sections 60 to 62 of the Australian Consumer Law.
1.6 Any variation to the scope of work must be agreed in writing by the Parties before the varied work is commenced. Variations may be subject to an adjustment of the Contract fee. Oral instructions for variations will not be acted upon.
1.7 The Landscaper will comply with all applicable laws, including the Work Health and Safety Act 2011 (Cth) or applicable state or territory WHS legislation, local council regulations, and any relevant planning or environment protection legislation in respect of works performed at the Property.
2. SCHEDULE AND COMPLETION
2.1 Works will commence on [Commencement Date] and are for [Engagement Term].
2.3 For ongoing maintenance arrangements, services will be provided [Maintenance Frequency] during daylight hours, unless otherwise agreed in writing.
2.4 The Client must provide the Landscaper with safe access to the Property at scheduled service times. The Landscaper will take reasonable precautions to protect existing structures, garden features, and utilities during works.
3. FEES AND PAYMENT
3.1 In consideration for performance of the services, the Client shall pay the Landscaper [Fee Amount] on [Fee Structure] basis. All fees are [GST Treatment].
3.2 A deposit of $[Deposit Amount] is payable upon signing of this Contract to secure the Landscaper’s availability and procure materials. The deposit will be applied against the total Contract fee.
3.3 The Landscaper will issue a valid tax invoice in accordance with the A New Tax System (Goods and Services Tax) Act 1999 (Cth). All tax invoices include the Landscaper’s ABN.
3.4 The Client must pay each invoice within [Payment Terms] days of the invoice date by electronic funds transfer to the bank account nominated by the Landscaper.
3.5 If any invoice remains unpaid after the due date, the Landscaper may charge interest at 10% per annum, calculated daily, and may suspend works on 5 business days’ written notice until all outstanding amounts are paid.
3.6 The Client is responsible for obtaining, at its own cost, all local council approvals, development approvals, and permits required for the works before commencement. Works will not commence until required approvals are in place.
4. WARRANTIES AND DEFECTS LIABILITY
4.1 The Landscaper warrants that all work performed under this Contract will be: (a) carried out in a good and workmanlike manner; (b) in compliance with applicable laws and relevant Australian Standards; and (c) using materials that are new, fit for purpose, and of acceptable quality.
4.2 The Landscaper will rectify, at no additional cost to the Client, any defect in workmanship notified by the Client within [Warranty Period] months of the date of practical completion. This clause does not apply to damage caused by the Client, third parties, Acts of God, or failure by the Client to properly maintain completed works.
4.3 Plants supplied and planted by the Landscaper are warranted to be of acceptable quality at the time of planting, but the Landscaper does not warrant plant survival beyond the date of handover, as plant health is affected by conditions outside the Landscaper’s control including irrigation, soil conditions, and weather.
4.4 Nothing in this clause limits, restricts, or modifies the consumer guarantees implied by the Australian Consumer Law that cannot lawfully be excluded or limited.
5. INSURANCE AND WORK HEALTH AND SAFETY
5.1 The Landscaper must maintain, throughout the term of this Contract: (a) public liability insurance with a minimum cover of $10,000,000 (AUD) per occurrence; and (b) where the Landscaper employs workers, workers’ compensation insurance as required by applicable state or territory legislation.
5.2 The Landscaper must provide evidence of current insurance certificates within 5 business days of the Client’s request.
5.3 The Landscaper must comply with the Work Health and Safety Act 2011 (Cth) and applicable state or territory WHS legislation in performing all works at the Property. The Landscaper is responsible for the health and safety of its employees, subcontractors, and agents on site.
5.4 The Client acknowledges its obligations as a person in control of a workplace under applicable WHS legislation and must disclose all known hazards at the Property before work commences.
6. AUSTRALIAN CONSUMER LAW
6.1 Nothing in this Contract excludes, restricts, or modifies any right, remedy, guarantee, warranty, or other term implied or imposed by the Australian Consumer Law (Schedule 2 of the Competition and Consumer Act 2010 (Cth)) that cannot lawfully be excluded or limited.
6.2 To the maximum extent permitted by law, the Landscaper’s aggregate liability to the Client for any claim arising under or in connection with this Contract is limited to the total fees paid by the Client under this Contract.
7. TERMINATION
7.1 For ongoing maintenance arrangements: either Party may terminate this Contract for convenience by giving [Notice Period] days’ written notice to the other Party.
7.2 Either Party may terminate this Contract immediately by written notice if the other Party commits a material breach that is not remedied within 14 days of written notice requiring remedy, or if the other Party becomes insolvent.
7.3 If the Client terminates a one-time project contract after works have commenced, the Client must pay: (a) all fees for work completed up to the date of termination; (b) the cost of all materials ordered or delivered for the project; and (c) a reasonable sum for lost profit and demobilisation costs.
7.4 Termination does not affect any accrued rights or liabilities of either Party.
8. GENERAL PROVISIONS
8.1 Entire Agreement: This Contract constitutes the entire agreement between the Parties with respect to the landscaping services and supersedes all prior representations and agreements.
8.2 Amendments: This Contract may only be amended by a written instrument signed by both Parties.
8.3 Independent Contractor: The Landscaper is an independent contractor and not an employee of the Client.
8.4 Dispute Resolution: If a dispute arises, the Parties must attempt good-faith negotiation within 14 days of written notice. If unresolved, either Party may refer the matter to mediation before commencing legal proceedings.
8.5 Governing Law: This Contract is governed by the laws of [Governing State], Australia. Each Party submits to the non-exclusive jurisdiction of the courts of [Governing State] and the Federal Court of Australia.
8.6 Severability: If any provision is invalid or unenforceable, the remaining provisions continue in full force and effect.
EXECUTED as a Contract.
LANDSCAPER
Name: [Landscaper Name]
ABN: [Landscaper ABN]
Address: [Landscaper Address], [Landscaper Suburb], [Landscaper State] [Landscaper Postcode]
CLIENT
Name: [Client Name]
Address: [Client Address], [Client Suburb], [Client State] [Client Postcode]
Landscaper
________________
Signature
Date: ________________
Client
________________
Signature
Date: ________________
What Is a Service Contract for Landscaping Services (Australia)?
A Service Contract for Landscaping Services in Australia records the landscaping work to be provided, the fees, the service standards, and each party's obligations between the provider and the client. The agreement is governed by the common law of contract and, where services are supplied to a consumer, the Australian Consumer Law (Schedule 2 of the Competition and Consumer Act 2010 (Cth)).
Landscaping contracts are governed by the Australian Consumer Law (ACL), Schedule 2 of the Competition and Consumer Act 2010 (Cth), which implies non-excludable consumer guarantees into every landscaping services contract. The Work Health and Safety Act 2011 (Cth) and its state and territory equivalents impose safety obligations on both the landscaper and the client as controller of the workplace. Building and contractor licensing legislation in each state and territory may also require certain landscaping work above value thresholds to be performed by a licensed contractor.
The Australia Service Contract for Landscaping Services (Australia) template is suitable for residential garden design and construction, commercial grounds maintenance, lawn care and turf management, irrigation installation, retaining wall and paving construction, and general landscaping services across all Australian states and territories. It accommodates both one-time projects and ongoing maintenance arrangements.
The legal framework governing the Service Contract for Landscaping Services (Australia) in Australia draws on several key statutes and regulatory bodies. Under the Corporations Act 2001 (Cth), the Australian Securities and Investments Commission (ASIC) regulates companies and financial services. Section 127 of the Corporations Act 2001 governs company execution of documents. The Australian Competition and Consumer Commission (ACCC) enforces the Competition and Consumer Act 2010 (Cth). The Australian Taxation Office (ATO) administers the Goods and Services Tax under the A New Tax System (Goods and Services Tax) Act 1999. The Federal Court of Australia and Supreme Courts of each state have jurisdiction over corporate disputes. Parties executing a Service Contract for Landscaping Services (Australia) in Australia should confirm the document reflects current law, including any amendments enacted since the original drafting date. The Corporations Act 2001 (Cth) sets the foundational requirements.
When Do You Need a Service Contract for Landscaping Services (Australia)?
A written Service Contract for Landscaping Services should be used for any landscaping engagement with a value or ongoing nature that warrants legal protection. Verbal agreements are enforceable but difficult to prove — a written contract is the clearest evidence of what was agreed.
A landscaping contract is particularly important for: large-scale residential or commercial landscaping projects involving design, earthworks, construction, and planting; ongoing garden maintenance arrangements where regular access, clear scope, and predictable pricing are required; projects involving installation of irrigation systems, retaining walls, paving, or other constructed elements that may require council approval or contractor licensing; commercial properties, strata schemes, or shopping centres where the client has procurement and insurance compliance requirements; and any engagement where a deposit is required, as the contract documents the deposit terms and cancellation rights.
For landscaping businesses, a written contract protects against scope creep, non-payment, delayed commencement, and disputes about the quality of materials or plants. For clients, a written contract confirms the scope of work, price, completion date, and warranty terms are clearly documented before work begins.
Parties in Australia should prepare a Service Contract for Landscaping Services (Australia) proactively rather than waiting for a dispute to arise. Courts interpret agreements based on the written terms rather than oral representations. Under the Corporations Act 2001 (Cth), the Australian Securities and Investments Commission (ASIC) regulates companies and financial services. Section 127 of the Corporations Act 2001 governs company execution of documents. The Australian Competition and Consumer Commission (ACCC) enforces the Competition and Consumer Act 2010 (Cth). The Australian Taxation Office (ATO) administers the Goods and Services Tax under the A New Tax System (Goods and Services Tax) Act 1999. The Federal Court of Australia and Supreme Courts of each state have jurisdiction over corporate disputes. Where the transaction involves regulated activities, prior approval from the relevant authority may be required before execution.
What to Include in Your Service Contract for Landscaping Services (Australia)
A thorough Australian Service Contract for Landscaping Services should include the following key elements.
Parties and ABN: Full legal names and Australian Business Numbers, enabling valid tax invoices and demonstrating the commercial nature of the engagement.
Scope of work: A detailed, specific description of all work to be performed. Reference plans, drawings, and plant lists where available. Clearly distinguish between works included and excluded. A vague scope of work is the primary cause of landscaping disputes.
Materials provision: Whether the landscaper supplies all materials at quoted rates, the client supplies materials with the landscaper providing labour only, or materials are shared as per a schedule. Specify brands or grades where quality standards are important.
Contractor licence: The landscaper's contractor licence number and issuing authority, where the work requires a licence under applicable state or territory legislation.
Schedule and completion: The commencement date and estimated completion date for projects, or the maintenance frequency for ongoing arrangements. Include a variation mechanism for delays due to weather, materials, or other circumstances beyond the landscaper's control.
Fees, deposit, and GST: The total project fee or ongoing maintenance rate, the deposit amount, whether GST is included or additional, the invoicing schedule, and the payment due period.
Council approvals: Allocation of responsibility for obtaining required development approvals, tree removal permits, and council consents before work commences.
Warranties and defects: The workmanship warranty period, the scope of the warranty, and the distinction between workmanship defects (landscaper's liability) and plant failure after handover (client's responsibility, subject to ACL guarantees).
Insurance and WHS: Public liability insurance obligations, workers' compensation where applicable, WHS compliance duties of both parties, and hazard disclosure requirements.
Termination: Notice periods for ongoing arrangements, consequences of client-initiated project cancellation after commencement, and payment obligations on termination.
Additional compliance elements for a Service Contract for Landscaping Services (Australia) used in Australia include: Under the Corporations Act 2001 (Cth), the Australian Securities and Investments Commission (ASIC) regulates companies and financial services. Section 127 of the Corporations Act 2001 governs company execution of documents. The Australian Competition and Consumer Commission (ACCC) enforces the Competition and Consumer Act 2010 (Cth). The Australian Taxation Office (ATO) administers the Goods and Services Tax under the A New Tax System (Goods and Services Tax) Act 1999. The Federal Court of Australia and Supreme Courts of each state have jurisdiction over corporate disputes. Forms-legal.com provides this template as a starting point for Australia-compliant documentation.
Cite this page
Reference this free template in an article, syllabus, or research note:
Forms Legal. (2026). Service Contract for Landscaping Services (Australia) (Australia) [Legal document template]. Forms Legal. https://forms-legal.com/australia/business/services/service-contract-landscaping-australia
"Service Contract for Landscaping Services (Australia) (Australia)." Forms Legal, 2026, https://forms-legal.com/australia/business/services/service-contract-landscaping-australia.
@misc{formslegal-service-contract-landscaping-australia,
author = {{Forms Legal}},
title = {Service Contract for Landscaping Services (Australia) (Australia)},
year = {2026},
howpublished = {\url{https://forms-legal.com/australia/business/services/service-contract-landscaping-australia}},
note = {Free legal document template. Based on Common law of contract; Australian Consumer Law (Competition and Consumer Act 2010 (Cth) Sch 2)}
}Frequently Asked Questions
Contractor licensing requirements for landscapers vary by state and territory and depend on the nature and value of the work. In New South Wales, landscaping work that involves construction — such as retaining walls above 600mm, paving, or water features — may require a contractor licence from NSW Fair Trading under the Home Building Act 1989 (NSW). In Victoria, domestic building work above the relevant threshold requires registration with the Victorian Building Authority (VBA) under the Domestic Building Contracts Act 1995 (VIC). In Queensland, residential construction work (including paving, retaining walls, and structures) above $3,300 requires a Queensland Building and Construction Commission (QBCC) licence. In Western Australia, similar requirements apply under the Building Services (Registration) Act 2011 (WA). Landscaping work limited to planting, mowing, pruning, and soft landscaping typically does not require a contractor licence, but landscapers should confirm their specific obligations with the relevant state or territory licensing authority before entering into construction contracts.
Landscaping services are subject to the consumer guarantees implied by the Australian Consumer Law (Schedule 2 of the Competition and Consumer Act 2010 (Cth)), which require that services be performed with due care and skill (s 60) and that materials supplied (including plants, soil, and pavers) be of acceptable quality (s 54). For construction-related landscaping work in New South Wales, the Home Building Act 1989 (NSW) implies statutory warranties including that work will be done with due care and skill, in accordance with the plans and specifications, and with materials suitable for the purpose and of good quality. Similar implied warranties exist under the Domestic Building Contracts Act 1995 (VIC) in Victoria. These statutory warranties typically run for defined periods — often 6 years for major defects and 2 years for minor defects in NSW — and are in addition to any contractual warranty offered by the landscaper.
Obtaining required council approvals, development consents, and tree removal permits is generally the client's responsibility, unless the landscaping contract expressly provides otherwise. Works such as significant earthworks, retaining walls above height limits, removal of protected trees, installation of swimming pools, or construction of structures may require development approval under applicable state planning legislation — including the Environmental Planning and Assessment Act 1979 (NSW), the Planning and Environment Act 1987 (VIC), or similar legislation in other jurisdictions — and local government development control plans. Work should not commence until all required approvals are in place. If the client fails to obtain required approvals and work is ordered to be removed or remedied by a council or court, the cost of removal and reinstatement will generally be the client's liability.
A landscaping contract can limit liability for plant failure after the handover date, provided the limitation is reasonable and consistent with the Australian Consumer Law. The landscaper can warrant that plants are of acceptable quality at the time of planting (consistent with the ACL guarantee under s 54), but cannot guarantee plant survival beyond handover because survival depends on irrigation, soil conditions, weather, pest pressure, and the client's ongoing maintenance — all factors outside the landscaper's control. A reasonable contractual clause distinguishing between the workmanship warranty (which applies to the manner of planting and the quality of plants at delivery) and the client's responsibility for plant care after handover is generally enforceable. However, such a clause cannot exclude the ACL consumer guarantees for consumer clients, and if plants clearly fail due to the landscaper's poor planting technique or supply of diseased stock, the consumer may still have a remedy under the ACL.
Landscaping services — including labour and materials — are taxable supplies under the A New Tax System (Goods and Services Tax) Act 1999 (Cth) and are subject to 10% GST where the landscaping business is registered for GST. Registration is mandatory for businesses with annual GST turnover of $75,000 or more. The landscaping contract must clearly state whether the quoted price is inclusive or exclusive of GST. If the price is exclusive of GST, the client will pay an additional 10% on top. For fixed-price projects, the contract should specify whether materials are included in the quoted price and how variations in material costs will be handled. The landscaper must issue valid tax invoices for each payment, including the business's ABN and the GST amount. Clients who are GST-registered may be entitled to claim input tax credits on the GST included in the landscaping invoice.
This template is provided for informational purposes only and does not constitute legal advice. Laws vary by jurisdiction and change over time. Consult a qualified attorney for advice specific to your situation.Full disclaimer
Found an error? Let us knowRelated Documents
You may also find these documents useful:
Service Agreement (Australia)
Create a comprehensive Australian Service Agreement compliant with the Australian Consumer Law (Schedule 2 of the Competition and Consumer Act 2010 (Cth)) and the common law of contract. Covers scope of services, GST-inclusive or exclusive fees, payment terms, consumer guarantees, intellectual property ownership, confidentiality, Privacy Act 1988 obligations, limitation of liability, and termination rights. Suitable for consultants, freelancers, agencies, and businesses providing services to other businesses or consumers across all Australian states and territories.
Service Contract for Cleaning Services (Australia)
A professionally drafted Service Contract for Cleaning Services provides a comprehensive legal foundation for cleaning businesses and their clients across Australia, covering commercial and residential cleaning engagements of all types. Whether you operate as a sole trader cleaner, a cleaning franchise, an end-of-lease specialist, or a large commercial cleaning company, a properly structured written contract protects your business, reduces disputes, and ensures both parties understand their rights and obligations before work begins. In Australia, cleaning service contracts are governed principally by the Australian Consumer Law (ACL), which is Schedule 2 of the Competition and Consumer Act 2010 (Cth). The ACL applies in all states and territories and implies mandatory consumer guarantees into every contract for services supplied to consumers. Under sections 60 to 62 of the ACL, cleaning services must be performed with due care and skill, must be fit for any particular purpose made known to the supplier, and must be completed within a reasonable time where no time is agreed. These guarantees are non-excludable — any term in a cleaning contract that attempts to exclude them is void under section 64 of the ACL. Since 9 November 2023, the ACL's unfair contract terms provisions (Part 2-3) have been extended to apply to small business contracts, meaning that standard form cleaning contracts used with small business clients may be scrutinised for unfair terms. A term is unfair if it creates a significant imbalance in the parties' rights and obligations, is not reasonably necessary to protect legitimate interests, and would cause detriment if relied upon. Cleaning businesses should ensure their standard contracts are balanced and transparent. Work health and safety obligations are a critical feature of any cleaning contract in Australia. Under the Work Health and Safety Act 2011 (Cth) and its state and territory equivalents — including the Work Health and Safety Act 2011 (NSW), the Occupational Health and Safety Act 2004 (VIC), the Work Health and Safety Act 2011 (QLD), and similar legislation across other jurisdictions — cleaning businesses have a primary duty of care to ensure the health and safety of their workers. Clients who control a workplace also have duties as persons in control of a business or undertaking (PCBUs). A cleaning contract should address access, hazard disclosure, and WHS compliance to protect both parties. Public liability insurance is essential for cleaning businesses. The industry standard minimum is $10,000,000 per occurrence. Many commercial property managers, body corporate operators, and facility managers will not permit a cleaning contractor on site without a current certificate of currency. If the cleaning business employs workers, workers' compensation insurance is mandatory under state and territory legislation, including the Workers Compensation Act 1987 (NSW), the Workplace Injury Rehabilitation and Compensation Act 2013 (VIC), and equivalent legislation in each jurisdiction. GST applies to cleaning services at 10% where the provider is registered for GST. Registration is compulsory for businesses with annual GST turnover of $75,000 or more under the A New Tax System (Goods and Services Tax) Act 1999 (Cth). Valid tax invoices must include the provider's ABN, separately identify the GST amount, and comply with the GST Act. The cleaning contract must clearly state whether the agreed rate is inclusive or exclusive of GST to prevent invoicing disputes. For residential cleaning, privacy considerations are particularly important because cleaners work inside clients' homes and may observe or have access to personal property and confidential information. The Privacy Act 1988 (Cth) and its 13 Australian Privacy Principles apply to businesses with annual turnover exceeding $3 million, but best practice requires all cleaning businesses to maintain confidentiality obligations regardless of size. The cleaning contract should include explicit confidentiality provisions binding the cleaner and its personnel. End-of-lease and bond cleaning is a common source of disputes between tenants, landlords, and cleaning companies. State residential tenancy legislation — including the Residential Tenancies Act 2010 (NSW), the Residential Tenancies Act 1997 (VIC), and equivalent legislation across Australia — governs bond deductions and the required standard of cleanliness. A detailed scope of work, photographic records before and after cleaning, and a clear contract are the best protections for cleaning businesses in this segment. This template is suitable for use across all Australian states and territories and for both one-time and ongoing cleaning arrangements. The governing law clause allows the parties to select the applicable jurisdiction, and the dispute resolution clause directs parties to state consumer protection authorities as the first step in resolving any dispute.
Independent Contractor Agreement (Australia)
Create a legally compliant Independent Contractor Agreement for Australia. Covers ABN requirements, sham contracting protections, GST, IP ownership, WHS obligations, and the multi-factor contractor test under Fair Work Act 2009. Suitable for all states and territories including NSW, VIC, QLD, WA, SA, and ACT.
Subcontractor Agreement (Australia)
Create a legally compliant Subcontractor Agreement for the Australian building and construction industry. Covers Security of Payment Act rights, payment claims, adjudication, retention, defects liability, variations, WHS obligations, public liability and workers' compensation insurance. Suitable for all states and territories.
Liability Waiver (Australia)
Protect your business from liability for recreational activities under Australian law. Covers Australian Consumer Law (ACL) limitations on excluding liability, section 139A CCA 2010 recreational services exception, voluntary assumption of risk, Civil Liability Acts (state-specific), contributory negligence, indemnity, and photo/media consent.