Freelance Contract — Australia (Creative, Tech & Professional Services)
Independent Contractor Agreement — Creative, Tech & Professional Services
This Freelance Contract (the “Agreement”) is made on [Agreement Date] between:
[Client Name] (ABN [Client ABN]), of [Client Address], [Client City] [Client State] [Client Postcode] (the “Client”); and
[Freelancer Name] (ABN [Freelancer ABN]), of [Freelancer Address], [Freelancer City] [Freelancer State] [Freelancer Postcode] (the “Freelancer”).
The Client and the Freelancer are referred to collectively as the “Parties”.
BACKGROUND
A. The Client wishes to engage the Freelancer to provide [Service Category] for the project known as [Project Name] (the “Project”), on an independent contractor basis.
B. The Freelancer carries on an independent business and is willing to provide the Services on the terms and conditions of this Agreement.
C. The Parties confirm this Agreement creates a genuine independent contractor relationship and is not intended to create an employment relationship. The Parties are aware of the sham contracting provisions in Part 3-1, Division 6 of the Fair Work Act 2009 (Cth) (s357–359). The maximum civil penalty for sham contracting is $469,500 for a body corporate (as at 27 February 2024).
1. NATURE OF RELATIONSHIP
1.1 The Freelancer is engaged as an independent contractor and not as an employee, worker, agent, or partner of the Client.
1.2 The Freelancer is not entitled to any benefits or protections applicable to employees under the Fair Work Act 2009 (Cth), including annual leave, personal leave, long service leave, parental leave, redundancy pay, or notice of termination under the National Employment Standards.
1.3 The Freelancer represents and warrants that they hold a valid ABN ([Freelancer ABN]) and operate as a genuine independent business. The Freelancer controls their own work methods, hours, tools, and location, subject to agreed deadlines and deliverables.
1.4 The Freelancer may work for other clients during the term of this Agreement, provided this does not cause a breach of the Freelancer’s confidentiality obligations or give rise to a material conflict of interest.
2. PROJECT SCOPE AND SERVICES
2.1 The Freelancer agrees to provide the following [Service Category] for the Project (the “Services”):
[Services Description]
2.2 The Freelancer shall perform the Services to a professional standard consistent with the skill and care ordinarily exercised by a competent freelancer in the relevant field.
2.3 Any changes to the scope of the Services must be agreed in writing by both Parties before the Freelancer commences additional work. Additional work outside the agreed scope will be charged at the rate set out in clause 4.5.
3. PROJECT TIMELINE
3.1 The Project commences on [Start Date] and will be delivered on a [Timeline Type] basis. The expected project completion date is [Completion Date].
3.2 Time is not of the essence unless the Client has notified the Freelancer in writing that a specific deadline is critical. The Freelancer will notify the Client as soon as reasonably practicable if a delay in delivery is anticipated.
4. FEES AND PAYMENT
4.1 In consideration for the performance of the Services, the Client will pay the Freelancer on a [Fee Structure] basis, at the rate of [Fee Amount].
4.2 Payment is due within [Payment Terms] of receipt of a valid tax invoice from the Freelancer.
4.3 All fees are in Australian Dollars (AUD). The Freelancer is solely responsible for all income tax, Medicare levy, and other government charges on amounts received.
4.4 If the Client fails to pay a valid invoice by the due date, interest will accrue on the outstanding amount at the rate of [Late Payment Rate], calculated from the due date until the date of payment.
4.5 Additional revisions or work outside the agreed scope will be charged at [Additional Revision Rate], by separate invoice.
5. REVISIONS AND SCOPE CHANGES
5.1 The agreed fee includes [Revisions Included] round(s) of revisions per deliverable, based on consolidated feedback provided in a single communication per round.
5.2 Additional revision rounds or changes that fall outside the agreed scope will be treated as additional work and charged at [Additional Revision Rate]. The Freelancer will notify the Client in writing before commencing any out-of-scope work.
5.3 Fundamental changes to the project brief that require substantial rework of completed deliverables may be treated as a new engagement at the Freelancer’s discretion.
6. INTELLECTUAL PROPERTY
6.1 [IP Owner].
6.2 The Freelancer warrants that the deliverables and all intellectual property created in performing the Services will not infringe the intellectual property rights of any third party, and that the Freelancer has the right to assign or licence the IP as set out in this clause.
6.3 Until all fees have been paid in full, the Freelancer retains all intellectual property in work completed under this Agreement, and grants the Client a limited, non-exclusive, non-transferable licence to use deliverables already provided solely for the purposes contemplated by this Agreement. Full assignment of IP (where applicable) occurs only upon receipt of payment in full.
6.4 Moral rights: To the extent permitted by the Copyright Act 1968 (Cth), the Freelancer consents to the Client reproducing, adapting, or attributing the deliverables without identifying the Freelancer as author.
7. TERMINATION
7.1 Either party may terminate this Agreement by giving [Notice Days] calendar days’ written notice to the other party.
7.2 Either party may terminate this Agreement immediately by written notice if the other party: (a) commits a material breach that is incapable of remedy, or fails to remedy a material breach within 7 days of written notice; or (b) becomes insolvent or bankrupt.
7.3 On termination before project completion, the Freelancer is entitled to a pro-rata fee for work completed and deliverables accepted up to the date of termination. Any non-refundable deposit is retained by the Freelancer. The Client is not entitled to use any incomplete deliverables until all outstanding fees are paid.
8. DISPUTE RESOLUTION
8.1 The Parties agree to attempt to resolve any dispute by good faith negotiation within 14 days of written notice of the dispute.
8.2 If unresolved, either party may refer the dispute to mediation administered by an agreed mediator or the Australian Disputes Centre. The costs of mediation are shared equally unless otherwise agreed.
9. GENERAL PROVISIONS
9.1 Governing Law. This Agreement is governed by the laws of [Governing State], Australia. The Parties submit to the exclusive jurisdiction of the courts of [Governing State].
9.2 Entire Agreement. This Agreement constitutes the entire agreement between the Parties and supersedes all prior representations and understandings.
9.3 Amendments. No amendment is effective unless in writing and signed by both Parties.
9.4 Severability. If any provision is void or unenforceable, it may be severed without affecting the remaining provisions.
9.5 Consumer Law. Nothing in this Agreement excludes, restricts, or modifies any right or remedy, or any guarantee, warranty, or other term or condition, implied or imposed by the Australian Consumer Law (Schedule 2 to the Competition and Consumer Act 2010 (Cth)) to the extent that such exclusion would be void or prohibited.
EXECUTED as an Agreement on the date first written above.
CLIENT
[Client Name]
ABN: [Client ABN]
Address: [Client Address], [Client City] [Client State] [Client Postcode]
FREELANCER
[Freelancer Name]
ABN: [Freelancer ABN]
Address: [Freelancer Address], [Freelancer City] [Freelancer State] [Freelancer Postcode]
Client
________________
Signature
Date: ________________
Freelancer
________________
Signature
Date: ________________
What Is a Freelance Contract — Australia (Creative, Tech & Professional Services)?
A Freelance Contract — Australia (Creative, Tech & Professional Services) in Australia engages an independent contractor to deliver defined work and records the scope, fees, intellectual-property ownership, and confidentiality terms, with the contractor's status distinguished from employment under the Fair Work Act 2009 (Cth).
In Australia, freelancers are independent contractors under the Fair Work Act 2009 (Cth). The distinction between an employee and a freelancer is critically important because it determines whether the engaging party has obligations under the National Employment Standards (NES), including annual leave, personal leave, superannuation, and redundancy pay. Following the landmark High Court decisions in CFMMEU v Personnel Contracting Pty Ltd (2022) 275 CLR 165 and ZG Operations Australia Pty Ltd v Jamsek (2022) 275 CLR 254, the primary test for contractor versus employee status focuses on the terms of the written contract — making a well-drafted Freelance Contract the most important document in the relationship.
Australian Freelance Contracts have several distinctive features required by local law. ABN and GST provisions are unique to Australia: the freelancer must hold a valid ABN, and those with GST turnover of $75,000 or more must register for GST and issue valid tax invoices. Intellectual property provisions are particularly important: under s35(2) of the Copyright Act 1968 (Cth), copyright in work created by a freelancer belongs to the freelancer by default, and the client must obtain an express written assignment if it requires ownership of the deliverables. Sham contracting declarations protect both parties against a finding that the arrangement is actually an employment relationship, with maximum civil penalties of $469,500 per contravention for a body corporate under the Fair Work Act 2009.
The Australia Freelance Contract — Australia (Creative, Tech & Professional Services) Freelance Contract is suitable for graphic designers, web developers, software engineers, copywriters, content creators, photographers, videographers, social media managers, marketing consultants, UX/UI designers, illustrators, and all creative and professional freelancers operating across Australia.
The legal framework governing the Freelance Contract — Australia (Creative, Tech & Professional Services) in Australia draws on several key statutes and regulatory bodies. Under the Fair Work Act 2009 (Cth), the Fair Work Commission (FWC) adjudicates workplace disputes. Section 394 of the Fair Work Act 2009 governs unfair dismissal claims. The Fair Work Ombudsman (FWO) enforces compliance with the National Employment Standards (NES). The Privacy Act 1988 (Cth) and Australian Privacy Principles (APPs) govern personal data handling. The Australian Taxation Office (ATO) administers PAYG withholding and superannuation guarantee obligations under the Superannuation Guarantee (Administration) Act 1992. Parties executing a Freelance Contract — Australia (Creative, Tech & Professional Services) in Australia should confirm the document reflects current law, including any amendments enacted since the original drafting date. The Fair Work Act 2009 (Cth) sets the foundational requirements.
When Do You Need a Freelance Contract — Australia (Creative, Tech & Professional Services)?
You need a Freelance Contract whenever you engage a freelancer for a specific project or ongoing work. The contract is equally important for the client and the freelancer.
For the client, the contract documents the scope of work, the deliverables, the project timeline, the fees, the payment terms, and who owns the intellectual property in the work produced. Without a written contract, the client may not own the copyright in commissioned creative work (because it belongs to the freelancer by default under Australian copyright law), may have no remedy for late or non-delivery of work, and may face disputes about what was included in the agreed fee.
For the freelancer, the contract protects their entitlement to the agreed fee, limits their revision obligations to the agreed number of rounds, protects their right to use completed work in their portfolio, establishes a late payment interest clause to incentivise prompt payment, and retains their copyright in work until the fee is paid in full. Without a written contract, freelancers frequently face scope creep, delayed payment, and disputes about what was agreed.
Common situations requiring a Freelance Contract in Australia include: commissioning a graphic designer to create a logo, brand identity, or marketing materials; engaging a web developer to build a website, e-commerce store, or web application; hiring a photographer or videographer for a commercial shoot; retaining a copywriter to produce website content, blog posts, or advertising copy; engaging a social media manager to create and manage content; hiring an IT specialist or software developer for a technology project; and retaining a marketing or SEO consultant for a defined campaign.
A signed Freelance Contract prevents the most common freelance disputes — scope creep, late payment, IP ownership confusion, and disagreements about revisions — and provides a clear legal framework for resolving any disputes that do arise.
What to Include in Your Freelance Contract — Australia (Creative, Tech & Professional Services)
A well-drafted Freelance Contract for Australia must address several key elements that are specific to the Australian legal and commercial environment.
Project scope and deliverables must be defined with precision. Vague project descriptions are the single biggest cause of scope creep and payment disputes. The contract should specify exactly what will be delivered, in what format, by when, and how it will be deemed accepted by the client.
Milestone-based payments and deposit provisions protect the freelancer from non-payment. A deposit of 25%–50% of the total project fee before work commences is standard practice for Australian freelancers. Milestone payments tied to delivery and client approval of specific deliverables confirm the freelancer is paid as work progresses, rather than only at the end of the project.
A late payment interest clause is an important commercial protection. Interest accruing from the due date of an unpaid invoice incentivises prompt payment and provides the freelancer with compensation for the cost of being out of pocket.
Intellectual property provisions must be carefully drafted. Because copyright belongs to the freelancer by default under s35(2) of the Copyright Act 1968 (Cth), the contract must either: (a) contain an express IP assignment clause transferring copyright to the client upon full payment of fees; or (b) clearly state that the freelancer retains copyright and grants the client a licence to use the work. Many freelance contracts also distinguish between background IP (pre-existing tools, code libraries, design elements, and methodologies) and foreground IP (work created specifically for the client), with background IP remaining with the freelancer and only foreground IP being assigned or licensed to the client. A payment-conditional IP provision — under which full assignment of IP occurs only upon receipt of payment in full — provides an important incentive for prompt payment.
A revision policy limits the freelancer's obligation to revise completed work. The contract should specify the number of revision rounds included in the agreed fee, the process for requesting revisions, and the hourly or daily rate for additional revision rounds or out-of-scope changes. Moral rights provisions under the Copyright Act 1968 (Cth) should also be addressed, particularly for creative freelancers.
GST and ABN provisions are mandatory for Australian freelance contracts, given the unique requirements of Australian tax law for independent contractors.
Additional compliance elements for a Freelance Contract — Australia (Creative, Tech & Professional Services) used in Australia include: Under the Fair Work Act 2009 (Cth), the Fair Work Commission (FWC) adjudicates workplace disputes. Section 394 of the Fair Work Act 2009 governs unfair dismissal claims. The Fair Work Ombudsman (FWO) enforces compliance with the National Employment Standards (NES). The Privacy Act 1988 (Cth) and Australian Privacy Principles (APPs) govern personal data handling. The Australian Taxation Office (ATO) administers PAYG withholding and superannuation guarantee obligations under the Superannuation Guarantee (Administration) Act 1992. Forms-legal.com provides this template as a starting point for Australia-compliant documentation.
Cite this page
Reference this free template in an article, syllabus, or research note:
Forms Legal. (2026). Freelance Contract — Australia (Creative, Tech & Professional Services) (Australia) [Legal document template]. Forms Legal. https://forms-legal.com/australia/employment/contractor-agreements/freelance-contract-australia
"Freelance Contract — Australia (Creative, Tech & Professional Services) (Australia)." Forms Legal, 2026, https://forms-legal.com/australia/employment/contractor-agreements/freelance-contract-australia.
@misc{formslegal-freelance-contract-australia,
author = {{Forms Legal}},
title = {Freelance Contract — Australia (Creative, Tech & Professional Services) (Australia)},
year = {2026},
howpublished = {\url{https://forms-legal.com/australia/employment/contractor-agreements/freelance-contract-australia}},
note = {Free legal document template. Based on Fair Work Act 2009 (Cth)}
}Also available for these jurisdictions:
Frequently Asked Questions
Under s35(2) of the Copyright Act 1968 (Cth), copyright in works created by an independent contractor (including a freelancer) belongs to the freelancer by default — not to the client. This is different from the position for employees, where copyright in works created during employment generally belongs to the employer under s35(6). The only exceptions for contractors are works created under contract for newspapers, magazines, or similar periodicals for publication, and portraits, photographs, or engravings commissioned and paid for by the client. For all other freelance work — including website designs, logos, illustrations, code, written content, video, and photography for general commercial purposes — the client must obtain an express written assignment of copyright in the contract if it requires ownership of the deliverables. A licence to use the work is not the same as ownership and does not transfer copyright. This is one of the most frequently misunderstood aspects of freelance law in Australia, and one of the most important reasons to have a written Freelance Contract with a clear IP clause.
Independent freelancers are generally required to hold an Australian Business Number (ABN) if they are carrying on a business. Under s12-35 of Schedule 1 to the Taxation Administration Act 1953 (Cth), if a freelancer does not quote an ABN when invoicing a business, the business may be required to withhold 47% (the top marginal rate plus Medicare levy) of the gross payment and remit it to the ATO. This withholding does not apply where the freelancer quotes their ABN, provides a Statement by a Supplier, or the payment is subject to another withholding arrangement. Freelancers with annual GST turnover of $75,000 or more are also required to register for GST and must charge GST at 10% on their fees, issuing valid tax invoices. Freelancers below the $75,000 threshold may voluntarily register for GST but are not required to do so. Having an ABN and registering for GST (where required) are important indicators of genuine independent contractor status.
A client's right to terminate a Freelance Contract and their obligations upon termination depend on the terms of the contract. Under a well-drafted Freelance Contract, the client may terminate the contract by giving the agreed notice period (typically 7–14 days). However, the freelancer is generally entitled to payment for work properly performed up to the date of termination, calculated on a pro-rata basis for fixed-fee projects. A non-refundable deposit is typically retained by the freelancer on termination. A client who terminates the contract without cause and refuses to pay for work completed may face a claim for breach of contract. In Australia, disputes about unpaid freelance fees can be brought in the relevant state or territory's civil tribunal (such as NCAT in NSW, VCAT in Victoria, or QCAT in Queensland) for smaller amounts, or in the Magistrates or Local Court for larger claims. Australian Consumer Law (ACL) guarantees of acceptable quality and fitness for purpose apply to services supplied in trade or commerce, regardless of contractual terms.
Scope creep occurs when the scope of a freelance project expands beyond what was originally agreed — often through incremental requests for additional work, changes to the brief, or extra revision rounds — without a corresponding increase in fees. It is one of the most common and costly problems in freelance work. A well-drafted Freelance Contract prevents scope creep by: (1) defining the project deliverables specifically and in writing; (2) specifying the number of revision rounds included in the fee; (3) establishing a clear process for approving out-of-scope work requests in writing before the freelancer commences additional work; and (4) specifying the hourly or daily rate at which additional work will be charged. The contract should make clear that any changes to the project scope that are not agreed in writing are not binding on the freelancer. A written change request and approval process — even if conducted by email — is essential for managing scope changes in practice. The freelancer should stop work on any out-of-scope request until a written variation has been agreed and signed.
A freelancer must charge GST if their annual GST turnover is $75,000 or more. GST turnover includes all amounts received for freelance services in Australia, not just income from a single client. Freelancers who meet this threshold must register for GST with the ATO, charge 10% GST on their fees, issue valid tax invoices that meet the requirements of the A New Tax System (Goods and Services Tax) Act 1999 (Cth) (GST Act), and lodge regular Business Activity Statements (BAS). Freelancers with turnover below $75,000 may voluntarily register for GST. If registered, the client can claim an input tax credit on the GST paid, reducing the effective cost of the GST. A valid tax invoice must include: the words 'Tax Invoice'; the supplier's name and ABN; the date; a description of the supply; the price (clearly showing the GST component); and, for invoices of $1,000 or more, the recipient's name. Providing an incorrect or incomplete tax invoice can result in the client being unable to claim input tax credits and may attract ATO penalties.
This template is provided for informational purposes only and does not constitute legal advice. Laws vary by jurisdiction and change over time. Consult a qualified attorney for advice specific to your situation.Full disclaimer
Found an error? Let us knowRelated Documents
You may also find these documents useful:
Independent Contractor Agreement (Australia)
Create a legally compliant Independent Contractor Agreement for Australia. Covers ABN requirements, sham contracting protections, GST, IP ownership, WHS obligations, and the multi-factor contractor test under Fair Work Act 2009. Suitable for all states and territories including NSW, VIC, QLD, WA, SA, and ACT.
Consultancy Agreement (Australia)
Create a professional Consultancy Agreement for Australia. Covers scope of services, fixed or hourly fees, GST, expense reimbursement, IP ownership, confidentiality, liability cap, professional indemnity insurance, and Australian Consumer Law compliance. Suitable for all states and territories.
Independent Contractor Agreement for Consulting Services (Australia)
Create a legally compliant Independent Contractor Agreement for Consulting Services tailored to Australian law. Covers sham contracting compliance under Fair Work Act 2009 (s357–359), ABN and GST requirements, intellectual property assignment, professional indemnity insurance, restraint of trade, and confidentiality. Suitable for management consultants, IT consultants, marketing advisors, financial advisors, engineering consultants, and other professional service providers. Complies with the High Court contractor test established in CFMMEU v Personnel Contracting Pty Ltd (2022) 275 CLR 165.
Virtual Assistant Contract (Australia)
Create a legally compliant Virtual Assistant Contract tailored to Australian law. Covers sham contracting compliance (Fair Work Act 2009 s357–359), ABN and GST requirements, data privacy and security (Privacy Act 1988, Australian Privacy Principles), system access and credentials, confidentiality, social media authority, response time commitments, and superannuation. Suitable for remote virtual assistants providing administrative, executive support, social media, calendar management, and general business support services across Australia.
Non-Disclosure Agreement (NDA) (Australia)
Protect your confidential business information under Australian common law with a legally sound Non-Disclosure Agreement (NDA). Whether you are sharing trade secrets with a prospective partner, disclosing proprietary technology to a developer, or presenting financial projections to a potential investor, a properly drafted Australian NDA keeps your sensitive information under strict legal protection. Our template complies with Australian contract law principles and includes provisions addressing the Privacy Act 1988 (Cth) and the Australian Privacy Principles.